Look-up in Google Scholar
Title: Análisis del Caso Arbitral N° 2728-2013-CCL: Deficiencias en la motivación del Laudo y las repercusiones al Equilibrio Económico Financiero del Contrato N° 022-2010-GOBIERNO REGIONAL DEL CALLAO, por causas imputables a La Entidad
Advisor(s): Chocano Davis, Christian César
OCDE field: https://purl.org/pe-repo/ocde/ford#5.05.01
Issue Date: 8-Aug-2023
Institution: Pontificia Universidad Católica del Perú
Abstract: En el presente trabajo se analiza la controversia suscitada entre el Gobierno Regional del Callao y el Consorcio Nueva Gambetta, la cual fue resuelta en el proceso arbitral N° 2728-2013-CCL. El argumento principal del Consorcio (demandante) se basó en que por razones imputables al Gobierno Regional del Callao (demandado), hubo atrasos en la ejecución de obras, generando una modificación en el plazo contractual y, por lo tanto, consecuencias en el aspecto económico del Contrato. Es así que, se presentan cinco pretensiones, siendo la cuarta sobre el pago de los Costos Directos que se habrían computado por la inactividad y/o paralización de equipos empleados en obra, a raíz de que la Entidad no entregó los terrenos en los que se realizaría la obra, liberados, sin interferencias y de acuerdo al plazo pactado en el Contrato. A partir de ello, se analizan las cláusulas del Contrato, la metodología para el cálculo de los Costos Directos, la regulación de este concepto en la Ley de Contrataciones aplicable, así como de las posteriores modificaciones hasta la fecha. De igual manera, se estudia la preservación del Equilibrio Económico Financiero del Contrato, el respeto al Principio de Equidad, la modificación a la figura de la entrega parcial de terrenos y el sistema de contratación elegido. Finalmente, el trabajo concluye que el deber de motivación en el laudo es imprescindible para fundamentar las decisiones adoptadas por el Tribunal Arbitral y con ello, evitar que se generen causales de anulación de laudo

This paper analyses the controversy between the Regional Government of Callao and the Nueva Gambetta Consortium, which was resolved in arbitration process No. 2728-2013-CCL. The main argument of the Consortium (plaintiff) was based on the fact that, due to the Regional Government of Callao's (defendant) attributable reasons, there were delays in the execution of works, resulting in a modification of the contractual deadline and, therefore, economic consequences under the Contract. As a result, five claims are presented, with the fourth one concerning the payment of Direct Costs that would have been incurred due to the inactivity and/or immobilization of equipment used in the project, as a result of the Entity not delivering the lands where the works would take place, cleared, without interference, and according to the agreed deadline in the Contract. Based on this, the clauses of the Contract, the methodology for calculating Direct Costs, the regulation of this concept in the applicable Contracting Law, as well as subsequent amendments up to the date, are analysed. Likewise, the preservation of the Economic and Financial Equilibrium of the Contract, respect for the Principle of Equity, the modification to the partial delivery of lands, and the chosen contracting system are studied. Finally, the paper concludes that the duty of motivation in the arbitral award is essential to substantiate the decisions made by the Arbitral Tribunal and thereby prevent grounds for annulment of the award
Discipline: Derecho
Grade or title grantor: Pontificia Universidad Católica del Perú. Facultad de Derecho
Grade or title: Abogado
Juror: Moscol Salinas, Alejandro Martin; Díaz Montalvo, Jorge Armando
Register date: 8-Aug-2023; 8-Aug-2023



This item is licensed under a Creative Commons License Creative Commons