Buscar en Google Scholar
Registro completo de metadatos
Shimabukuro Makikado, Roberto Carlos
Silva Santisteban Amésquita, Massiel Kenyi
2022-08-15T16:39:31Z
2022-08-15T16:39:31Z
2022-08-15T16:39:31Z
2022-08-15T16:39:31Z
2022
2022-08-15
http://hdl.handle.net/20.500.12404/23082
This report addresses the interpretation made by the Tribunal of the arbitration between Obrascón Huarte Lain S.A. and Provías Nacional, regarding the requirements for an extension of time under construction contracts. This analysis is important as it shows that the government entity's position could generate perverse incentives to delay the arbitration. Likewise, it addresses the analysis carried out by the Peruvian Superior Court regarding the government entity's claim for annulment, in the sense that the award should have been annulled due to incongruous, apparent and defective motivation. The report concludes, on the one hand, that the requirements for an extension of time must be analyzed considering the opportunity in which they were presented and not the date on which the award is issued; and, on the other hand, that in order to consider that an arbitral award is motivated, a certain extension of the grounds for the decision is not needed. What must be verified is that there is motivation (legal basis); consistency and non-contradiction; and, sufficiency of the motivation, which did occur in the award subject to analysis. (es_ES)
El presente informe aborda la interpretación realizada por el Tribunal Arbitral del arbitraje seguido entre Obrascón Huarte Lain S.A. y Provías Nacional, respecto a los requisitos para una de ampliación de plazo bajo contratos de obra. Este análisis resulta importante en tanto pone en evidencia que la posición de la entidad podría generar incentivos perversos para la dilatación del arbitraje. De igual modo, aborda el análisis realizado por la Corte Superior respecto a la demanda de anulación de la entidad, en el sentido de que el laudo debió anularse por padecer de una motivación incongruente, aparente y defectuosa. En el informe se concluye, por un lado, que los requisitos para que proceda una ampliación de plazo deben analizarse considerando la oportunidad en que fueron presentados y no la fecha en que se emite el laudo; y, por otra parte, que para considerar que un laudo arbitral sí está motivado, no se necesita una determinada extensión. Lo que se debe verificar es que exista motivación (fundamentación jurídica); congruencia y no contradicción; y, suficiencia de la motivación, lo que sí ocurrió en el Laudo materia de análisis. (es_ES)
spa (es_ES)
Pontificia Universidad Católica del Perú (es_ES)
info:eu-repo/semantics/closedAccess (es_ES)
Contratos públicos--Perú (es_ES)
Arbitraje comercial--Jurisprudencia--Perú (es_ES)
Resolución N° 8 derivada de la controversia surgida entre Obrascón Huarte Lain S.A. y Provías Nacional (es_ES)
info:eu-repo/semantics/bachelorThesis (es_ES)
Pontificia Universidad Católica del Perú. Facultad de Derecho. (es_ES)
Derecho (es_ES)
Título Profesional (es_ES)
Abogado (es_ES)
PE (es_ES)
https://purl.org/pe-repo/ocde/ford#5.05.01 (es_ES)
https://purl.org/pe-repo/renati/level#tituloProfesional (es_ES)
07455380
https://orcid.org/0000-0002-9252-9766 (es_ES)
46674277
215106 (es_ES)
Moscol Salinas, Alejandro Martín (es_ES)
Shimabukuro Makikado, Roberto Carlos (es_ES)
Danós Ordóñez, Jorge Elías (es_ES)
https://purl.org/pe-repo/renati/type#trabajoDeSuficienciaProfesional (es_ES)
Privada asociativa



IMPORTANTE
La información contenida en este registro es de entera responsabilidad de la universidad, institución o escuela de educación superior que administra el repositorio académico digital donde se encuentra el trabajo de investigación y/o proyecto, los cuales son conducentes a optar títulos profesionales y grados académicos. SUNEDU no se hace responsable por los contenidos accesibles a través del Registro Nacional de Trabajos de Investigación – RENATI.