Bibliographic citations
Erausquin, M., (2024). Informe Jurídico sobre la Resolución Nº 46 Laudo Arbitral - Arbitraje Ad Hoc seguido entre OBRASCÓN HUARTE LAIN S.A. y PROVÍAS NACIONAL [Pontificia Universidad Católica del Perú]. http://hdl.handle.net/20.500.12404/28595
Erausquin, M., Informe Jurídico sobre la Resolución Nº 46 Laudo Arbitral - Arbitraje Ad Hoc seguido entre OBRASCÓN HUARTE LAIN S.A. y PROVÍAS NACIONAL []. PE: Pontificia Universidad Católica del Perú; 2024. http://hdl.handle.net/20.500.12404/28595
@misc{renati/532899,
title = "Informe Jurídico sobre la Resolución Nº 46 Laudo Arbitral - Arbitraje Ad Hoc seguido entre OBRASCÓN HUARTE LAIN S.A. y PROVÍAS NACIONAL",
author = "Erausquin Herrada, María José",
publisher = "Pontificia Universidad Católica del Perú",
year = "2024"
}
This legal report addresses one main problem and three secondary problems related to Resolution No. 46 Arbitration Award - Ad Hoc Arbitration followed between OBRASCÓN HUARTE LAIN S.A. and PROVIAS NACIONAL. The main problem lies in the possible alteration of the critical path of the project. It is concluded that there is an impact on the critical path, contrary to what the Arbitration Court indicates. The first secondary problem regarding the impact of the critical path due to the behavior of a third party unrelated to the work contract, is determined to be possible, since the delay in the approval of Additional Budget Nº 10 by the Comptroller General's Office the Republic constitutes a cause not attributable to the contractor. The second secondary problem refers to when an additional budget that exceeds 15% of the contractual amount is considered approved. It is established that the approval is given from the issuance of the resolution by the Comptroller General of the Republic, which provides for the approval of the additional budget requested by the contracting entity. The third secondary problem analyzes whether the contractor should request an extension of the deadline for additional work without the approval of the Comptroller General of the Republic. It is concluded that it is not possible, since, without said approval, the additional cannot be executed or the contractor be forced to request the extension of the deadline.
This item is licensed under a Creative Commons License