Look-up in Google Scholar
Title: Informe Jurídico sobre el Laudo Arbitral N°122-2010 (Consorcio JOHESA UPACA contra el Proyecto especial de infraestructura de transporte nacional-PROVIAS NACIONAL)
Advisor(s): Martin Tirado, Richard James
OCDE field: https://purl.org/pe-repo/ocde/ford#5.05.01
Issue Date: 30-Jul-2024
Institution: Pontificia Universidad Católica del Perú
Abstract: El presente informe abarca el caso arbitral N°122-2010 seguido por el consorcio Johesa Upaca contra el Proyecto Especial de Infraestructura de Transporte Nacional – PROVIAS NACIONAL, mediante el cual se analiza la pretensión de consorcio a fin de determinar la irregularidad y extemporaneidad de la resolución que aprueba la liquidación del contrato de obra realizada por la Entidad y, a su vez, sobre el consentimiento de la liquidación de contrato presentado por el contratista. Para ello corresponde evaluar las liquidaciones de obra presentadas por las partes a fin de determinar cuál de ellas siguió el procedimiento regular establecido en la ley. Cabe señalar que dicho examen se realizará bajo el análisis de la normativa de contrataciones y adquisiciones del Estado y su reglamento aplicable al caso. Asimismo, corresponde analizar si un hallazgo de contraloría puede generar variaciones en una ampliación de plazo aprobada y consentida y a su vez determinar la competencia del Tribunal Arbitral para tratar el enriquecimiento sin causa frente a la indemnización solicitada por el demandante.

This report analyzes the arbitration case N°122-2010 followed by the consortium Johesa Upaca against the Special Project of National Transportation Infrastructure - PROVIAS NACIONAL, through which the consortium's claim is analyzed in order to determine the irregularity and untimeliness of the resolution approving the liquidation of the construction contract carried out by the Entity and, in turn, on the consent of the contract liquidation presented by the contractor. To this end, it is necessary to evaluate the work settlements submitted by the parties in order to determine which of them followed the regular procedure established by law. It should be noted that this examination will be carried out under the analysis of the State contracting and procurement rules and regulations applicable to the case. Likewise, it is necessary to analyze whether a comptroller's finding can generate variations in an approved and consented extension of time and, in turn, to determine the competence of the Arbitral Tribunal to deal with the unjust enrichment in relation to the compensation requested by the claimant.
Discipline: Derecho
Grade or title grantor: Pontificia Universidad Católica del Perú. Facultad de Derecho.
Grade or title: Abogado
Juror: Gamio Aita, Pedro Fernando; Moscol Salinas, Alejandro Martín; Martin Tirado, Richard James
Register date: 30-Jul-2024



This item is licensed under a Creative Commons License Creative Commons